Terms and Conditions
Terms of Using Our Website and Services
Plain language. No legal jargon. Everything you need to know about using our website and working with Arush Solar Tech.
Introduction
These terms and conditions govern your use of www.arushsolartech.com and any services provided by Arush Solar Tech. By accessing our website or engaging our services you agree to these terms. If you do not agree please do not use our website or services.
These terms and conditions govern your use of www.arushsolartech.com and any services provided by Arush Solar Tech. By accessing our website or engaging our services you agree to these terms. If you do not agree please do not use our website or services.
About Our Services
Arush Solar Tech provides the following services:
Solar panel sales, domestic rooftop solar installation, professional rooftop solar installation, commercial rooftop solar installation, solar electric fencing, and solar street light installation across Bengaluru and Karnataka.
All services are subject to a separate written agreement or proposal provided to you before work commences. These terms and conditions govern your general use of our website and initial engagement not the specific terms of your installation project which are covered in your individual proposal and agreement.
Arush Solar Tech provides the following services:
Solar panel sales, domestic rooftop solar installation, professional rooftop solar installation, commercial rooftop solar installation, solar electric fencing, and solar street light installation across Bengaluru and Karnataka.
All services are subject to a separate written agreement or proposal provided to you before work commences. These terms and conditions govern your general use of our website and initial engagement not the specific terms of your installation project which are covered in your individual proposal and agreement.
Website Use
You may use our website for lawful purposes only. You agree not to use our website in any way that causes or may cause damage to the website or impairment of its availability. You agree not to reproduce, duplicate, copy, or exploit any content from this website for commercial purposes without our written permission.
All content on this website including text, images, logos, and design elements is the property of Arush Solar Tech unless otherwise stated. Unauthorised use of our content is prohibited.
You may use our website for lawful purposes only. You agree not to use our website in any way that causes or may cause damage to the website or impairment of its availability. You agree not to reproduce, duplicate, copy, or exploit any content from this website for commercial purposes without our written permission.
All content on this website including text, images, logos, and design elements is the property of Arush Solar Tech unless otherwise stated. Unauthorised use of our content is prohibited.
Quote Requests and Site Surveys
Submitting a quote request or booking a free site survey through our website does not constitute a binding agreement or obligation on either party. A free site survey is provided at no cost and with no obligation to proceed.
A binding agreement for solar installation services is only created when both parties have signed a written proposal or work order and a deposit has been received where applicable.
Submitting a quote request or booking a free site survey through our website does not constitute a binding agreement or obligation on either party. A free site survey is provided at no cost and with no obligation to proceed.
A binding agreement for solar installation services is only created when both parties have signed a written proposal or work order and a deposit has been received where applicable.
Accuracy of Information
We make every effort to ensure the information on our website is accurate and up to date. However we do not guarantee the completeness or accuracy of any information including pricing estimates, savings projections, or technical specifications mentioned on the website. All specific figures are indicative only and subject to formal assessment and proposal.
We make every effort to ensure the information on our website is accurate and up to date. However we do not guarantee the completeness or accuracy of any information including pricing estimates, savings projections, or technical specifications mentioned on the website. All specific figures are indicative only and subject to formal assessment and proposal.
Installation Services, General Terms
Specific terms for each installation project including scope of work, payment schedule, warranty terms, timeline, and post-installation support are detailed in the individual project proposal provided to each customer. In the event of any conflict between these general terms and your individual project agreement, the individual project agreement takes precedence.
Specific terms for each installation project including scope of work, payment schedule, warranty terms, timeline, and post-installation support are detailed in the individual project proposal provided to each customer. In the event of any conflict between these general terms and your individual project agreement, the individual project agreement takes precedence.
Warranty
Solar panel performance warranties are provided by the panel manufacturer and are subject to the manufacturer's warranty terms. Installation workmanship warranty terms are specified in your individual project agreement. Arush Solar Tech's role in warranty claims is to facilitate and support specific manufacturer warranty terms apply to panels and equipment.
Solar panel performance warranties are provided by the panel manufacturer and are subject to the manufacturer's warranty terms. Installation workmanship warranty terms are specified in your individual project agreement. Arush Solar Tech's role in warranty claims is to facilitate and support specific manufacturer warranty terms apply to panels and equipment.
Limitation of Liability
Arush Solar Tech's liability in connection with any service is limited to the value of the specific service provided. We are not liable for any indirect, consequential, or incidental loss arising from the use of our website or services including loss of income, loss of data, or disruption to business operations.
We are not liable for delays or failures caused by circumstances beyond our reasonable control including but not limited to government approval delays, BESCOM processing timelines, weather conditions, or supply chain disruptions.
Arush Solar Tech's liability in connection with any service is limited to the value of the specific service provided. We are not liable for any indirect, consequential, or incidental loss arising from the use of our website or services including loss of income, loss of data, or disruption to business operations.
We are not liable for delays or failures caused by circumstances beyond our reasonable control including but not limited to government approval delays, BESCOM processing timelines, weather conditions, or supply chain disruptions.
BESCOM and Government Approvals
For grid-connected and hybrid solar systems, BESCOM net metering approval is required from the local electricity authority. While Arush Solar Tech manages the application process on your behalf, approval timelines are determined by BESCOM and are outside our control. We do not guarantee specific approval timelines.
For grid-connected and hybrid solar systems, BESCOM net metering approval is required from the local electricity authority. While Arush Solar Tech manages the application process on your behalf, approval timelines are determined by BESCOM and are outside our control. We do not guarantee specific approval timelines.
Governing Law
These terms and conditions are governed by the laws of India. Any disputes arising from these terms or your use of our services shall be subject to the exclusive jurisdiction of the courts of Bengaluru, Karnataka.
These terms and conditions are governed by the laws of India. Any disputes arising from these terms or your use of our services shall be subject to the exclusive jurisdiction of the courts of Bengaluru, Karnataka.
Changes to These Terms
We reserve the right to update these terms and conditions at any time. Updated terms will be posted on this page with a revised effective date. Continued use of our website after any changes constitutes acceptance of the updated terms.
We reserve the right to update these terms and conditions at any time. Updated terms will be posted on this page with a revised effective date. Continued use of our website after any changes constitutes acceptance of the updated terms.
Contact Us
For any questions about these terms and conditions contact:
Arush Solar Tech #291, Ground Floor, 6th Cross, 27th Main BTM Layout, 2nd Stage, Bengaluru – 560076 Karnataka, India Email: Support@Arushsolartech.com Phone: +91-9686260065 Contact Person: Somashekar N, Marketing Executive Direct: +91 78993 50511
For any questions about these terms and conditions contact:
Arush Solar Tech #291, Ground Floor, 6th Cross, 27th Main BTM Layout, 2nd Stage, Bengaluru – 560076 Karnataka, India Email: Support@Arushsolartech.com Phone: +91-9686260065 Contact Person: Somashekar N, Marketing Executive Direct: +91 78993 50511
Powering Karnataka's homes and businesses with clean, reliable solar energy.
Quick Links
Our Services
Copyright © 2026 arushsolartech
All Rights Reserved | Terms and Conditions | Privacy Policy
Quick Links
Our Services
Powering Karnataka's homes and businesses with clean, reliable solar energy.
Copyright © 2026 arushsolartech
All Rights Reserved | Terms and Conditions | Privacy Policy
Quick Links
Our Services
Powering Karnataka's homes and businesses with clean, reliable solar energy.
Copyright © 2026 arushsolartech
All Rights Reserved |